Betterment of gravel steep section on district road **** to concrete pavement ( 900m), from km **** to km **** in the umzumbe local municipality, durban region - grade 5ce or higher
BETTERMENT OF GRAVEL STEEP SECTION ON DISTRICT ROAD **** TO CONCRETE PAVEMENT 900M, FROM KM **** TO KM **** IN THE UMSUMBE LOCAL MUNICIPALITY, DURBAN REGION. FOR GRADE 5CE OR HIGHER Schedule A: Roadworks General Requirements and Provisions Contractors Establishment on Site and General Obligations Accommodation of Traffic Drains Concrete Kerbing and Channeling, Asphalt Berms, Chutes, Downpipes, as well as Concrete, Stone Pitched and Gabion Linings for Open Drains Commercial Materials Roadbed Road Pavement Layers Paver Laid Concrete Layers Finishing the Road and Road Reserve and Treating Old Roads Testing Materials and Judgement of Workmanship Summary of Sections Tender Summary
AI helper
This tender is for the betterment of a gravel steep section on District Road **** to a concrete pavement. The project is located in the Umzumbe Local Municipality, Durban Region, KwaZulu-Natal. Key aspects include: - Construction of a 160mm thick pavement layer. - Road prism drainage and improvements to drainage. - Construction of culvert pipe crossings and erosion protection measures. - Use of labour-enhanced construction methods as part of the Expanded Public Works Programme (EPWP). - Requirements for small contractor development and contract skills development goals. - Adherence to environmental management and health and safety specifications. - The tender closes on 16 April 2025.
The tender document mentions payment for work done under provisional sums and prime cost sums in accordance with clause 6. 6 of the General Conditions of Contract **** also details payment schedules for specific items like training venue facilities and contract participation goals.
The contractor shall be responsible for maintaining the road from the date of handover until the issue of the certificate of practical completion, and undertaking maintenance work during the defect liability period.
The tender document mentions financial penalties for shortfalls in local labour content achieved and for failure to achieve contract participation goal targets.
The contractor shall carry out at his own cost the required process control testing as specified in terms of the standard specifications.
Disputes shall be referred to ad hoc adjudication, and unresolved disputes shall be determined by court proceedings.
BETTERMENT OF GRAVEL STEEP SECTION ON DISTRICT ROAD D492 TO CONCRETE PAVEMENT ( 300m), FROM KM **** TO KM **** AND FROM **** TO **** IN THE UMZUMBE LOCAL MUNICIPALITY, DURBAN REGION. GRADE 4CE OR HIGHER
Betterment of gravel steep section to concrete pavement on D492 in the Ugu district under Umzumbe Local Municipality within the Durban region. Schedule A: Roadworks C1. 2 General Requirements and Provisions C1. 3 Contractors Establishment on Site and General on Site and General Obligations C1. 5 Accommodation of Traffic C3. 1 Drains C3. 2 Culverts C3. 3 Concrete Kerbing and Channeling, Asphalt Berms, Chutes, Downpipes, as well as Concrete, Stone Pitched and Gabion Linings for Open Drains C4. 4 Commercial Materials C5. 1 Roadbed C5. 3 Road Pavement Layers C6. 1 Paver Laid Concrete Layers C11. 9 Finishing the Road and Road Reserve and Treating Old Roads C20. 1 Testing Materials and Judgement of Workmanship
Echo taxilane pavement repairs at or tambo international
echo taxilane pavement repairs at or tambo international
AI helper
The tender is for echo taxilane pavement repairs at OR Tambo International Airport. Bids must be submitted by email to ***@***. *. * by 12 March 2026 at 12:00 PM. A compulsory briefing session is scheduled for 02 March 2026. Tenderers must ensure compliance with tax obligations and submit a tax compliance status pin. The successful bidder must ensure they have a fully completed and signed written contract post award. The tender is subject to the preferential procurement policy framework act, **** and the preferential procurement regulations. Only tenderers with a CIDB contractor grading of 3CE or higher may submit offers. Queries must be submitted by 06 March 2026. The tender will be awarded to the bidder with the highest score, considering price and specific goals.
The tender must be awarded to the bidder who scores the highest points, unless objective criteria in addition to those contemplated in the specific goals preference justify the award to another bidder. In line with the pppfa, the tender must be awarded to the bidder who scores the highest points, unless objective criteria in addition to those contemplated in the specific goals preference justify the award to another bidder.
Only tenderers who are a cidb contractor grading of 3ce or higher as stated on the tender data may submit tender offers. only tenderers who are a cidb contractor grading of 3ce or higher as stated on the tender data may submittender offers.
A compulsory briefing/site inspection session is scheduled for 02 March 2026 at 12:00 PM at OR Tambo International Airport. briefingsite inspection session requirements detail date 02 march 2026 time 12: 00pm venue or tambo international airport media room
The closing time for receipt of tenders is 12 march 2026 at 12h00 pm south african time. he closing time for receipt of tenders is 12 march 2026 at 12h00 pm south african time.
Rehabilitation of Kerk and Nyala Street General requirements and provision Contractors establishment on site and general obligations Accommodation of traffic Housing, offices and laboratory for the engineers site personnel Mass earthworks Crushedstone base Breaking up existing pavement layers Patching and repairing edge breaks Prime coat Asphalt base and surfacing Road markings Testing materials and workmanship
AI helper
The tender is for the rehabilitation of Kerk and Nyala Street. The opening date for the tender offers is 24 February 2026 at 12:00. The 80/20 scoring method will apply in the evaluation of bids. The tenderers must score a minimum of 56 points for the bid to be eligible. A compulsory meeting will be held for all tenderers. The successful bidder will be required to fill in and sign a written contract form. Bids must be delivered by the stipulated time to the correct address. Late bids will not be accepted for consideration. The employer will provide the successful tenderer with one paper copy of the signed contract. The time for achieving practical completion is 6 months. The penalty for failing to complete the works is R1,**** per day. The payment period is within 14 days of receipt by the employer of the payment certificate signed by the employers agent.
The contract shall be completed twenty four months of the commencement within 24 date.
The employer shall pay the amount due to the contractor within 14 days of receipt by the employer of the payment certificate signed by the employers agent.
The defects liability period is 12 months from the date of completion on all new installations.
The **** scoring method will apply in the evaluation of bids.
Tenderers must score a minimum of 56 points for the bid to be eligible.
The penalty for failing to complete the works is R1,**** per day.
upgrade of utrecht street C1. 2. 8 dayworks personnel C1. 3. 1 the contractors general obligations C1. 4. 1 site accommodation offices and conference room C1. 5. 1 accommodation of pedestrian and non motorised traffic **** above C4. 3. 1 additional material investigations C5. 4. 2 chemical stabilisation: chemical stabilisation 150mm layer of **** rollerpass compaction of an exposed pavement layer smooth drum vibratory rollers **** watering the exposed pavement layer **** removal of surplus material from site **** insitu reconstruction of a pavement layer using a recycler to construct a stabilised base layer chemically stabilised base layer compacted to 100 of mdd **** material shortfall or makeup material for base layer **** finishing the stabilised layer slush reconstructed section with: water **** excavate pavement layers for patching in existing pavements excavate the following layers: cemented layers with a surface area: not exceeding 20 m, including for edge repa
AI helper
The tender is for the upgrade of Utrecht Street, including road rehabilitation, signage, and road markings. Bidders must submit bids by **** at 12:00. The 80/20 scoring method will be used. The time and location for opening of the tender offers are: 1200hrs date : 26 april 2026 location: abaqulusi local municipalitys boardroom co mark and high streets, vryheid, 3100. The contract will be completed within twelve months of the commencement within date. The offered total of the prices inclusive of value added tax is:. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . rand in words r . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . in figures. The employer shall pay the amount due to the contractor within 30 days of receipt by the employer of the payment certificate signed by the employers agent. The contractor shall commence with carrying out the works upon written instruction from the employers agent to commence with the works. The contractor will provide a payment certificate with quantities to the employers agent before or on the 20th of every month. After the payment certificate has been approved by employers agent, the contractor must issue an original tax invoice compliant with sars requirements for valid tax invoice. The date of the original tax invoice must be date the employers agent approved the payment certificate. The certificate will then be ready for handing in to the employer. Payment will be made end of the following month. The contractor shall provide a return in detail in the form and at such intervals as the employers agent or his duly authorized representative may prescribe showing the supervisory staff and the numbers of the several classes of labour from time to time employed by the contractor on the site and such information respecting constructional plant, equipment and material as the employers agent or his duly authorized representative may require. The targets for employment are as follows: women: 55 youth: 40. The definition of youth being of an age up to and including 35 years. The unit of measurement is person days being the total number of persons in that category multiplied by the number of days worked by each person respectively.
The contract shall be completed within welve months of the commencement within date.
The employer shall pay the contractor within 30 days of receipt by the employer of the payment certificate signed by the employers agent.
The 80/20 scoring method will apply in the evaluation of bids.
The tender offers will only be accepted if the tenderer is registered with the construction industry development board in the contractor grading designation of 6ce or higher.
The penalty for failing to complete the works is 0. 05 of the offered total of prices excluding vat per calendar day.
Add keywords for your products or services. BidHits uses them to find relevant tenders and expand your results.
2
Start free and receive alerts
Start the 14-day free trial and get emails with tender links, documents or the official page.
3
Refine your feed
Adjust keywords, provinces, delivery times and email style. Remove what does not fit so your feed stays useful.
Trusted by businesses that sell to government
They deliver on their promises. The information is simple and straightforward.
G. G
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
Very good and accurate information about the tenders: consistent and precise.
We selected helpful reviews from real users. Order may change periodically.
The idea of ​​using a keyword and sending the information by email is very good.
U. Solutions
It is complete and optimal, it improves my time.
R. de L. Cruz
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
I am very satisfied; it's a very useful tool.
J. S. Garcia
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
It encompasses all portals in one place.
G. Ferrea
It's an extremely useful tool.
M. M. Alv
I’ve landed several contracts through this platform. There’s no need to search—they send the service notifications directly to you.
A. O. Scholl
Well-focused searches and highly professional service. It’s been very useful, and hiring you was the right decision. With agility and confidence in our market segment, it’s driving our revenue growth.
O. O. Padron
Excellent information. Just what I was looking for.
BidHits is a search and alert service for public tenders in South Africa. We monitor official sources daily and deliver relevant opportunities on the site and by email, with AI-assisted matching to reduce manual checking.
Enter your email and activate the trial. For 14 days you can use the features, create alerts and check relevance. If you do not subscribe at /subscription.php, the tenders list becomes limited. There are no automatic charges.
Start with keywords for your products or services. After signup, choose provinces, delivery times and email style. You can refine everything later if the results need adjustment.
Whenever possible, yes. Some official sources require login or block direct downloads; in those cases we link to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by province, procurement method, dates and value ranges. In settings you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
AI-assisted search can make mistakes. Improve relevance by adding more specific terms, removing broad terms and deleting results that do not fit. This helps keep your feed useful.
Yes. You can query tenders via API. Documentation is available at /api_integration.php. It is useful for CRM, BI and automations.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, contact us. During the free trial there is no auto-charge.
We monitor major official sources daily at national, provincial and municipal levels. Tenders are added as they are published on the source.
Plans start at R 710.00 per month, with options for different business needs and billing terms. Start with a free trial and evaluate the results before subscribing, with no automatic billing.
Add what you sell, receive AI-assisted tender alerts, open documents or the official page, and filter by province, method and value.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1093 active users, conducted through 04/09/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
