Supply and delivery of repairs and maintanance material
Supply and delivery of repairs and maintenance material 60mm chrome cylinder lock, 250mm kaufmann tee hinge black, white yale stainless steel straight cylinder lockset, 60mm heavyduty padlock abus 60mm brass, 20l walls and all exterior low sheen paint midlands marsh glez, 20l walls and ceilings smooth matt finish paint molucca epl, plexiglass sheet 12mm, masonry drill bit 5mm, 6mm, 8mm, 10mm, wood bit 3mm, 5mm, 6mm, 8mm, **** each, 5 each, iidmn310mm makita jig saw blade, max 90mm **** i115mm x 3mm cutting disc masonry and steel, 230mm x 3mm cutting disc masonry and steel, 20l rubberflex waterproofing paint charcoal, 250mm x 10m duramesh waterproofing membrane, 22mm copper tap, high quality steel head trimmer, **** brush cutter head trimmer with a nut, 15mm copper tap, heavy duty door closer 65kg, yale 300 series door closer, reusable corded earplugs box of 100, paint tray set 225mm mohair, paint brush 5 piece set, 20l thinners, 3. 5mm x 160m 2kg nylon trimmer line, 5l weed killer round up 360, 16l k
AI helper
Supply and delivery of repairs and maintenance material. Bids will be adjudicated in accordance with the municipality supply chain management policy and preferential procurement based on the 80/20 point system. Minimum of 50 points in functionality is required. Validity period is 30 days. Submit company registration, tax compliance status, certified ID copies, proof of CSD registration, and municipal rates and taxes clearance certificate. Late, incomplete, or unsigned bids will not be considered. Technical enquiries to Mr. A Qaba at 073 403 **** or ***@***. *. * enquiries to Mr. N Stemela at 078 112 **** or ***@***. *. * must be deposited in the bid box by 11 June 2026 at 12:00.
Quotations must be deposited in the bid box, at the offices of the emalahleni municipality, 37 Indwe road, cacadu, **** not later than 11 june 2026 at 12h00.
The bid will be adjudicated in accordance with the municipality supply chain management policy and the specific goal preferential procurement will be based on the 80/20 point system.
The bidder must achieve a minimum of 50 points in functionality to advance to the next stage of evaluation. Bidders must submit a company registration certificate, tax compliance status document, all directors certified ID copies, proof of full central supplier database registration, and municipal rates and taxes clearance certificate.
Failure to submit a municipal rates and taxes clearance certificate or lease agreement will result in disqualification. Late, telegraphic, facsimile, incomplete or unsigned bids will not be considered. Failure to complete all the supplementary information will result in bidder being deemed non-responsive.
Re- surface of existing tennis courts at vredenburg sportgrounds
Repair and resurface of tennis courts 1. The existing courts have a surface area of **** grass weeds from the court perimeter, playing area and apply weed killer poison treatment. 3. Clean court surface thoroughly, using high pressure water jet to remove all dirt an algae on court surface. 4. Treat all courts with an antifungi chemical, to destroy all black algae spores embedded in the surface. 5. Clean up and fill up expansion joints with a stable mixture or a crack filler 6. Repair the area between and outside the two courts. 7. Open all subsided areas and repair to playing court level with asphalt and seal with bitumen slurry and re compact to 99 modd aastho. 8. Apply and spread heavy duty fibreflex or similar approved resurfacing system. fibreflex or similar approved consists of the following: 1st layer apply 1 layer fibre reinforced bitumen latex slurry layer to levelled areas. 2nd layer apply one nonpigmented plasticized mastic filler coat, using coarse aggregate sand in conjunction with lo
AI helper
This tender is for the repair and resurfacing of tennis courts at Vredenburg Sportsgrounds. The scope of work includes weed removal, surface cleaning, antifungal treatment, expansion joint and subsided area repair, application of a resurfacing system, and painting of court lines. Tenderers must have a CIDB contractor grading designation of 1CE or higher. Compulsory documents include MBD 4, MBD 6. 1, MBD 8, MBD 9, proof of municipal accounts or lease agreements for the company and directors, company registration documents, CIDB registration, letter of good standing, and proof of at least three previously successfully completed projects of a similar nature within the past five years. A detailed work plan (Annexure A) must also be submitted. A compulsory site meeting will be held on Monday, 15 May 2026, at 10:00 at Vredenburg Sportsgrounds. Contractors must comply with safety regulations, have proper insurance and public liability cover, and are responsible for waste disposal. Quotations must be valid for at least 90 days.
The bid notice does not explicitly state a delivery deadline for the services. However, it mentions that the contractor must provide valid reasons in writing for delays in either commencing or completion of the work, and that the project manager has the right to cancel the order if reasons for delays are considered unacceptable.
The bid notice mentions that the successful bidder needs to ensure compliance with section 204 of the Value Added Tax (VAT) Act, 89 of ****, regarding tax invoices. It also states that failure to comply with the VAT invoice requirements will result in payments not being made timeously, and the municipality will not be liable for any late payments due to invalid tax invoices.
The bid notice states that quotations will be evaluated in terms of the 80/20 preference point system, considering price and specific goals such as BBBEE status level contribution and locality. The municipality also reserves the right to accept the whole or a part of the quote and does not bind itself to accept the lowest or any bid.
To be considered for the contract, tenderers must comply with minimum criteria including previous relevant experience (a minimum of three successfully completed projects of a similar nature within the past five years), CIDB contractor grading designation equal to or higher than 1CE, and submission of all compulsory documents as listed.
The bid notice mentions that non-compliant contractors will be fined for waste management issues. It also states that if specific goals are claimed or obtained fraudulently, or if contract conditions are not fulfilled, the organ of state may disqualify the person, recover costs, cancel the contract, and potentially restrict the tenderer from obtaining business from any organ of state for up to 10 years, or forward the matter for criminal prosecution.
A compulsory site meeting will be held on Monday, 15 May 2026, at 10:00 at Vredenburg Sportsgrounds, erf: ****, at the entrance gate of tennis courts, Church Street.
We selected helpful reviews from real users. Order may change periodically.
The idea of ​​using a keyword and sending the information by email is very good.
U. Solutions
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
The platform is very user-friendly.
N. Lobato
Excellent information. Just what I was looking for.
L. H. Borrelli
It encompasses all portals in one place.
G. Ferrea
Efficiency in search times.
R. Chavez
The search tool really works and satisfactorily meets our needs.
D. L. Cairuga
It’s one of the best platforms for searching bids.
M. R. De Lima
The information helps me submit my bids on time for tenders, and I also have readily available information on upcoming tenders. So far, I am very satisfied with what I have received.
M. A. Z. Armenta
The filtering is well done, and I also receive the tenders I can participate in directly in my email.
E. B. Da Fonseca
They notify me promptly when a contest is published.
L. Salazar
The search engine that finds what I'm looking for just by entering keywords
J. P. L. Construccion
Not only is the service excellent, but the support when I have questions is great too—the site has really impressed me.
BidHits is a search and alert service for public tenders in South Africa. We monitor official sources daily and deliver relevant opportunities on the site and by email, with AI-assisted matching to reduce manual checking.
Enter your email and activate the trial. For 14 days you can use the features, create alerts and check relevance. If you do not subscribe at /subscription.php, the tenders list becomes limited. There are no automatic charges.
Start with keywords for your products or services. After signup, choose provinces, delivery times and email style. You can refine everything later if the results need adjustment.
Whenever possible, yes. Some official sources require login or block direct downloads; in those cases we link to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by province, procurement method, dates and value ranges. In settings you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
AI-assisted search can make mistakes. Improve relevance by adding more specific terms, removing broad terms and deleting results that do not fit. This helps keep your feed useful.
Yes. You can query tenders via API. Documentation is available at /api_integration.php. It is useful for CRM, BI and automations.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, contact us. During the free trial there is no auto-charge.
We monitor major official sources daily at national, provincial and municipal levels. Tenders are added as they are published on the source.
Plans start at R 710.00 per month, with options for different business needs and billing terms. Start with a free trial and evaluate the results before subscribing, with no automatic billing.
Add what you sell, receive AI-assisted tender alerts, open documents or the official page, and filter by province, method and value.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1077 active users, conducted through 28/07/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
