Case Management Tenders

Payments shall be made promptly, but in no case later than 30 days after submission of an invoice or claim by the supplier. payments shall be made promptly by the purchaser, but in no case later than thirty 30 days after submission of an invoice or claim by the supplier.

Tenders will be evaluated according to the 80/20 preferential points system: 80 points for price and 20 points for specific goals. tenders will be evaluated according to the **** preferential points system.

Bidders must submit a valid professional indemnity insurance certificate with minimum value of R2,000,**** a copy of valid professional indemnity insurance certificate with a minimum value of r2 000 ****

Penalties calculated using current prime interest rate per day of delay. deduct from the contract price, as a penalty, a sum calculated on the delivered price of the delayed goods or unperformed services using the current prime interest rate calculated for each day of the delay

Failure to complete documents in black ink, retyping documents, missing pages, or unauthorized alterations may result in disqualification. the original tender document must be completed fully in black pen ink and signed by the authorised signatory to validate the tender. failure to do so may result in the disqualification of the tender.

The study must be completed within eight weeks from the inception meeting, with deliverables due at specified weeks: d1 inception report end of week 1, d2 interim progress briefing end of week 4, d3 draft report end of week 6, d4 stakeholder validation workshop week 7, and d5 final report and engagement pack end of week 8.

Payment milestones are proposed as 20 on approval of d1, 30 on approval of d3 and 50 on approval of d5, subject to confirmation by supply chain management.

Quotations will be evaluated on functionality, price and specific goals in accordance with the supply chain management policy and the Preferential Procurement Policy Framework Act.

Bidders must meet mandatory requirements including demonstrated experience in economic, investment or sectoropportunity assessments, technical expertise in dust and air quality management, and provide a company profile, including details of at least three comparable assignments completed within the past five years.

Failure to provide required proof documents will result in non-responsiveness: failure to provide the required proof will result in your response being nonresponsive. Required documents include active CSD registration, completed WCBD4, and valid B-BBEE certificate.

Bids must be placed in the bid box on or before 06 November 2026 at 12h00. bids clearly marked gas: **** supply of local government library 2026 edition must be placed in the bid box of the municipality on or before the 06 november 2026 at 12h00.

Payment within 30 days after receipt of invoice accompanied by delivery note. i undertake to make payment for the goodsworks delivered in accordance with the terms and conditions of the contract, within 30 thirty days after receipt of an invoice accompanied by the delivery note.

Warranty valid 12 months after delivery and acceptance, or 18 months after shipment, whichever concludes earlier. this warranty shall remain valid for twelve 12 months after the goods. . . have been delivered to and accepted at the final destination. . . or for eighteen 18 months after the date of shipment.

Evaluation on 80/20 points basis: 80 points for price, 20 points for preferential targeted goals. bids will be evaluated on the **** points basis, where 80 points will be allocated to price and 20 points allocated to preferential points targeted specific goals.

Bidders must submit tax compliance status PIN, CSD registration, company registration, and B-BBEE certificate. bidders are required to submit their unique personal identification number pin issued by sars and bidder must submit proof of bbbee status level contributor certificate.

Penalty calculated on delayed goods price using current prime interest rate per day of delay. the purchaser shall. . . deduct from the contract price, as a penalty, a sum calculated on the delivered price of the delayed goods. . . using the current prime interest rate calculated for each day of the delay.

Failure to complete MBD forms fully and sign them results in non-responsiveness. mbd forms which forms part of the bid document must be completed in full and be duly signed, failure to do this will result in the bidder being considered nonresponsive.

Responses must be submitted by the closing date. The closing date is 11 November 2026 at 11:00 AM. closing date: **** closing time: 11: 00 a. m.

Respondents must provide a company profile, evidence of organisational capability, relevant experience, financial standing, certifications and contactable references. a company profile and evidence of organisational capability, relevant experience, financial standing, certifications and contactable references

Service providers must demonstrate a minimum of five years experience in infrastructure funding, project finance, energy projects, municipal finance, development finance, climate finance or related fields. As stated: the service provider must demonstrate a minimum of five 5 years experience in infrastructure funding, project finance, energy projects, municipal finance, development finance, climate finance or related fields.