Eastern Cape - East London Industrial Development Zone Corporation - Agency Bids & RFPs

The closing time for receipt of tenders is 12h00 pm on 10 april 2026 The closing time for receipt of tenders is 12h00 pm on 10 april 2026.

The defects liability period is 12 months The defects liability period is 12 months.

The tender will be awarded to the bid with the highest number of points The tender will be awarded to the bid with the highest number of points.

Tenderers are required to submit a valid SARS tax clearance certificate with their tender, or the relevant SARS pin code which will allow the elidz to confirm the tenderers tax status online enderers are required to submit a valid sars tax clearance certificate with their tender, or the relevant sars pin code which will allow the elidz to confirm the tenderers tax status online.

A noncompulsory briefing with representatives of the employer will take place virtually via microsoft teams on 24 march 2026 starting at 12h00 a noncompulsory briefing with representatives of the employer will take place virtually via microsoft teams on 24 march 2026 starting at 12h00.

Questions relating to the tender will be accepted until 12h00 pm 30 march 2026 with responses by 31 march 2026 Questions relating to the tender will be accepted until 12h00 pm 30 march 2026 with responses by 31 march 2026.

The bid notice states that the services shall be completed by a specific date, which is not mentioned in the provided text. he parties agree to the commencement date of for the commencement of the services and accordingly the services shall be completed by.

The bid notice states that payment milestones will be attached to the service level agreement. payment milestones will be attached to the service level agreement.

The respondent must indicate which resources will be part of a project team. he respondent must indicate which resources will be part of a project team.

The bid notice states that an amount equal to one fourteen percent 114 of the contract value may be deducted per day by the client for each day falling after stipulated completion date, until the services are complete. should the service provider fail to complete the services or any part thereof before the date which is stipulated herein, an amount equal to one fourteen percent 114 of the contract value may be deducted per day by the client for each day falling after stipulated completion date, until the services are complete.

The bid notice states that the services shall be completed by a specific date, which is not mentioned in the provided text. 6. 2. should the service provider fail to complete the services or any part thereof before the date which is stipulated herein, an amount equal to one fourteen percent 114 of the contract value may be deducted per day by the client for each day falling after stipulated completion date, until the services are complete.

The bid notice states that payment will be due and payable once the service provider has performed the necessary deliverables set out in annexure 1 and has issued the correct invoice. 11. 2. payment will only be due and payable once the service provider has performed the necessary deliverables set out in annexure 1 and has issued the correct invoice.

The bid notice states that the service provider warrants that there is no conflict of interest between the client and itself and that it shall take steps to avoid any future potential conflict of interest. 21. 1. the service provider warrants that there is no conflict of interest between the client and itself and that it shall take steps to avoid any future potential conflict of interest.

The bid notice states that the elidz reserves the right not to award business to the highest scoring bidders where objective criteria justify the award to another bidder. 12. elidz reserves the right not to award business to the highest scoring bidders where objective criteria justify the award to another bidder.

The bid notice states that the service provider must be an established firm of attorneys that has rendered a good quality of services in the areas of administrative law as detailed under section 32. 1: scope of work. 2. 3 firm profile the service provider must be an established firm of attorneys that has rendered a good quality of services in the areas of administrative law as detailed under section 32. 1: scope of work.

The bid notice states that should the service provider fail to complete the services or any part thereof before the date which is stipulated herein, an amount equal to one fourteen percent 114 of the contract value may be deducted per day by the client for each day falling after stipulated completion date, until the services are complete. 6. 2. should the service provider fail to complete the services or any part thereof before the date which is stipulated herein, an amount equal to one fourteen percent 114 of the contract value may be deducted per day by the client for each day falling after stipulated completion date, until the services are complete.