Appointment of a service provider for cleaning and clearing of debris in gutters, downpipes and walls of the administration building and nokukhanya luthuli resource centre ( nlrc) building at luthuli museum
The provision of South Smokestack Repairs Grootvlei PowerStation for a period of 6 months
South Smoke Stack Repairs Removal and disposal of loose debris. Repairing of refractory brick wall. Repairing of access cat ladder to a usable condition. Procurement of all materials required to complete the works. Provide all necessary equipment, including safety equipment, tools and materials required for the works. Ensure that surrounding equipment and structures are not damaged during execution. Supplying material and the mixing and placing of the chosen repair product as described on the product manufacturers application manual and this specification. Supplying, fabricating, constructing, maintaining and removing temporary works, including false work and formwork. The quality control qc and testing of all material.
AI helper
This tender is for South Smoke Stack Repairs at Grootvlei Power Station. The scope of work includes removal and disposal of loose debris, repairing the refractory brick wall, and repairing the access cat ladder. The contractor must procure all necessary materials and provide all equipment, including safety equipment. Quality control and testing of all materials are required. The contract will be based on the NEC3 Engineering and Construction Contract. The employer is Eskom Holdings SOC Ltd. The law of the contract is the law of the Republic of South Africa. The language of the contract is English. The completion date for the whole of the works is to be determined. The defects date is 52 weeks after completion. Payments are assessed monthly, with a payment period of 60 days. Interest rates are specified for late payments. Dispute resolution will be through arbitration.
The bid notice does not explicitly state a definitive completion date for the whole of the works, but it does mention key dates and conditions to be met, including the completion of all works and the project schedule as per the accepted programme.
The bid notice states that the assessment interval for payments is between the 25th day of each successive month, and the period within which payments are made is 60 days.
The bid notice specifies that plant and materials used for the works are to bear no labelling other than the plant coding specified by the employer and that the contractor procures and stores all materials as per the recommendations stipulated in the materials data sheet. It also mentions that plant and materials procured carry a minimum of 52 weeks warranty or guarantee period due to defect or malfunction.
The bid notice mentions that the contractor must provide competent personnel with relevant post qualification experience, and that the construction manager must be professionally registered with SACPCMP or a similar professional body, and the engineer/technician must be professionally registered with the Engineering Council of South Africa. CIDB grading of 7GB is also mentioned.
The bid notice details delay damages of R10,**** per day for the completion of the whole of the works, not exceeding 10% of the activity. It also outlines low performance damages for various incidents, capped at 10% of the contract value in aggregate.
The bid notice does not indicate a mandatory or optional site visit.
The bid notice does not mention any requirement for sample submission.
The bid notice does not specify a deadline for challenging the bid.
Re- advertisement: renew licensing, support and maintenance of existing current cloud call centre and integrated ticketing solution for eight ( 08) users for a period of three years
Tender for subcontractors for routine road maintenance of national routes in ****: Plant hire, including a crane truck, mobile hydraulic lift, 8 kVA generator, and cable fault locator and the supply and delivery of LV cable joints, sleeves, ferrules, and related ****: Removal of concrete debris, excavation for cable trenches, and backfilling of excavated trenches. SC2061102: Supply and installation of materials and equipment for preventive maintenance work, welding and strapping of access points, and supply and installation of pole ****: Supply and installation of materials and equipment for preventive maintenance work, welding and strapping of access points, and supply and installation of pole ****: Supply and placement of concrete bedding and encasement of cables in the trench using class **** ****: Supply and installation of materials and equipment for preventive maintenance work, welding and strapping of access points, and supply and
AI helper
Tender for subcontractors. Mandatory briefing session on March 12, 2026. Closing date for submissions is March 26, 2026. Failure to submit Form A1. 1 by March 10, 2026, may result in the tenderer being deemed non-responsive. All submissions must be hand-delivered to the tender box.
The bid notice states that the closing time for receipt of tenders is 10h00 on 26 March 2026.
The tender invites tenders from EME subcontractors who are black youth, black women, black military veterans, or black persons with disabilities.
The tender notice mentions a compulsory briefing session.
Re- advertisement: clinical psychologist services for makhado local municipality employees for the period of three years.
Tender for subcontractors for routine road maintenance of national route N121, N41, and ****: Plant hire, including a crane truck, mobile hydraulic lift, 8 kVA generator, and cable fault locator and the supply and delivery of LV cable joints, sleeves, ferrules, and related ****: Removal of concrete debris, excavation for cable trenches, and backfilling of excavated trenches. SC2061102: Supply and installation of materials and equipment for preventive maintenance work, welding and strapping of access points, and supply and installation of pole ****: Supply and installation of materials and equipment for preventive maintenance work, welding and strapping of access points, and supply and installation of pole ****: Supply and placement of concrete bedding and encasement of cables in the trench using class **** ****: Supply and installation of materials and equipment for preventive maintenance work, welding and strapping of access points, and sup
Re- advertisement: construction, supply, delivery and installation of new weighbridge at makhado landfill site ( tshikota)
Tender for subcontractors for routine road maintenance of national route N121, N41, and ****: Plant hire, including a crane truck, mobile hydraulic lift, 8 kVA generator, and cable fault locator and the supply and delivery of LV cable joints, sleeves, ferrules, and related ****: Removal of concrete debris, excavation for cable trenches, and backfilling of excavated trenches. SC2061102: Supply and installation of materials and equipment for preventive maintenance work, welding and strapping of access points, and supply and installation of pole ****: Supply and installation of materials and equipment for preventive maintenance work, welding and strapping of access points, and supply and installation of pole ****: Supply and placement of concrete bedding and encasement of cables in the trench using class **** ****: Supply and installation of materials and equipment for preventive maintenance work, welding and strapping of access points, and sup
Add words related to your products or services. Our AI broadens the search so you don't miss opportunities.
2
Sign up and receive by email
Start the 14-day free trial and receive alerts with links to the documents and to the official page.
3
Adjust if needed
Add or edit keywords, set provinces, choose your delivery schedule and email style. A map view is available on the dashboard.
What our users say
90% recommend BidHits (1039 real users, 28/04/2026).Methodology
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
The idea of ​​using a keyword and sending the information by email is very good.
BidHits is a public tenders search engine. We map official portals daily and deliver results on the site and by email. Our AI understands your business so you don't miss opportunities.
Just enter your email and activate the trial. For 14 days you can use all features. When it ends, if you don't subscribe at /subscription.php, the tenders list becomes limited and there are no automatic charges.
1) Choose keywords (your products or services). 2) Activate the trial and start receiving. After signup you can adjust regions, times, and email style on the settings page.
Whenever possible, yes. Some official portals require login or block direct links; in those cases we point you to the official process page so you can download the documents.
Yes. In the tenders panel you can filter by region, procurement method, dates, and value ranges. In settings you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map in the panel and see tenders by location.
AI can make mistakes. It's trained to understand your business based on the keywords you add. Refine by adding specific terms, modifying or deleting those that produce off-topic results. That trains your feed and improves future alerts.
Yes. You can query tenders via API. Documentation at /api_integration.php. Ideal for CRM, BI and automations.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there's no auto-charge.
We monitor major official portals daily at the national, provincial and municipal levels. Tenders are added as soon as they are published on the source portal.
Plans start at R 710.00/month. Start with the free trial-- no automatic charges.
Explore a term, enable AI email alerts, access the tender documents or official portal, and filter by region and procurement method.
Transcript
Welcome to BidHits. Start by adding a few key words. Just type what you sell.
That's it. You're now ready to explore government contract opportunities made for you. Your bidding dashboard shows the latest tenders organized by date and matched to your keywords.
To help you spot the most relevant ones, your keywords are automatically highlighted in yellow.
And here's the best part. Our AI is always working behind the scenes to bring you even more opportunities.
Smart Search is already on, enhancing your results beyond exact matches. You don't have to do a thing.
Each tender card comes with useful tools. You can view a summary, open documents, favorite tenders, write private notes, remove what doesn't fit, or check the location on the map.
You can also see all tenders from the same day in a single map view. Perfect for planning your next steps. Use the search bar, apply filters, and explore with ease.
Try BidHits now. It's fast, smart, and free to get started.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1039 active users, conducted through 28/04/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".