Specialist Tenders

Proposals must be submitted electronically to ***@***. *. * by Thursday, 19 November 2026 at 16h30. closing date and time thursday, 19 november 2026@16h30

Bidders must be registered on National Treasury's Central Supplier Database (CSD). business may not be awarded to a respondent who has failed to register on the csd.

Late submissions, incorrect email, or failure to submit mandatory documents will lead to elimination. bidder that submit late bids will not be considered and bidder that did not submit mandatory returnable documents as listed on annexure e will be eliminated.

Eskom commits to paying suppliers within 30 days of receipt of undisputed invoices for contracts valued below R50 million. eskom is committed to paying suppliers within 30 days of receipt of undisputed invoices.

Tenders are ranked using the 80/20 preferential point scoring system, with price scored out of 80 points and specific goals out of 20 points. eskom will add the score from pricing and specific goals together and rank the suppliers from the highest to the lowest.

Tenderers must meet eligibility criteria, including CIDB contractor grading of 6ME or higher. tenderers must have a construction industry development board cidb contractor grading of 6me mechanical engineering me class of construction works or higher

A compulsory clarification site visit is scheduled for 06 November 2026 at Hendrina Power Station. a compulsory clarification site visit with representatives of eskom meeting will take place as follows: date: 06 november 2026 time: 09 am 12: 00 pm venue: hendrina power station

Clarification queries must be submitted five working days before the tender deadline, by 12 November 2026 at 15:30. the tenderer will notify eskom of any clarifications required before the closing time for clarification queries, which is five days 05 working days before the deadline for tender submission, 12 november 2026 @15: 30

Tenderers who fail to attend the mandatory site visit will be disqualified. tenderers who fail to attend a mandatory meeting will be disqualified and their tenders will not be considered for further evaluation.

Payments shall be made promptly, but in no case later than 30 days after submission of an invoice or claim by the supplier. payments shall be made promptly by the purchaser, but in no case later than thirty 30 days after submission of an invoice or claim by the supplier.

Tenders will be evaluated according to the 80/20 preferential points system: 80 points for price and 20 points for specific goals. tenders will be evaluated according to the **** preferential points system.

Bidders must submit a valid professional indemnity insurance certificate with minimum value of R2,000,**** a copy of valid professional indemnity insurance certificate with a minimum value of r2 000 ****

Penalties calculated using current prime interest rate per day of delay. deduct from the contract price, as a penalty, a sum calculated on the delivered price of the delayed goods or unperformed services using the current prime interest rate calculated for each day of the delay

Failure to complete documents in black ink, retyping documents, missing pages, or unauthorized alterations may result in disqualification. the original tender document must be completed fully in black pen ink and signed by the authorised signatory to validate the tender. failure to do so may result in the disqualification of the tender.