Betterment of gravel steep section on district road **** to concrete pavement ( 900m), from km **** to km **** in the umzumbe local municipality, durban region - grade 5ce or higher
BETTERMENT OF GRAVEL STEEP SECTION ON DISTRICT ROAD **** TO CONCRETE PAVEMENT 900M, FROM KM **** TO KM **** IN THE UMSUMBE LOCAL MUNICIPALITY, DURBAN REGION. FOR GRADE 5CE OR HIGHER Schedule A: Roadworks General Requirements and Provisions Contractors Establishment on Site and General Obligations Accommodation of Traffic Drains Concrete Kerbing and Channeling, Asphalt Berms, Chutes, Downpipes, as well as Concrete, Stone Pitched and Gabion Linings for Open Drains Commercial Materials Roadbed Road Pavement Layers Paver Laid Concrete Layers Finishing the Road and Road Reserve and Treating Old Roads Testing Materials and Judgement of Workmanship Summary of Sections Tender Summary
AI helper
This tender is for the betterment of a gravel steep section on District Road **** to a concrete pavement. The project is located in the Umzumbe Local Municipality, Durban Region, KwaZulu-Natal. Key aspects include: - Construction of a 160mm thick pavement layer. - Road prism drainage and improvements to drainage. - Construction of culvert pipe crossings and erosion protection measures. - Use of labour-enhanced construction methods as part of the Expanded Public Works Programme (EPWP). - Requirements for small contractor development and contract skills development goals. - Adherence to environmental management and health and safety specifications. - The tender closes on 16 April 2025.
The tender document mentions payment for work done under provisional sums and prime cost sums in accordance with clause 6. 6 of the General Conditions of Contract **** also details payment schedules for specific items like training venue facilities and contract participation goals.
The contractor shall be responsible for maintaining the road from the date of handover until the issue of the certificate of practical completion, and undertaking maintenance work during the defect liability period.
The tender document mentions financial penalties for shortfalls in local labour content achieved and for failure to achieve contract participation goal targets.
The contractor shall carry out at his own cost the required process control testing as specified in terms of the standard specifications.
Disputes shall be referred to ad hoc adjudication, and unresolved disputes shall be determined by court proceedings.
BETTERMENT OF GRAVEL STEEP SECTION ON DISTRICT ROAD D492 TO CONCRETE PAVEMENT ( 300m), FROM KM **** TO KM **** AND FROM **** TO **** IN THE UMZUMBE LOCAL MUNICIPALITY, DURBAN REGION. GRADE 4CE OR HIGHER
Betterment of gravel steep section to concrete pavement on D492 in the Ugu district under Umzumbe Local Municipality within the Durban region. Schedule A: Roadworks C1. 2 General Requirements and Provisions C1. 3 Contractors Establishment on Site and General on Site and General Obligations C1. 5 Accommodation of Traffic C3. 1 Drains C3. 2 Culverts C3. 3 Concrete Kerbing and Channeling, Asphalt Berms, Chutes, Downpipes, as well as Concrete, Stone Pitched and Gabion Linings for Open Drains C4. 4 Commercial Materials C5. 1 Roadbed C5. 3 Road Pavement Layers C6. 1 Paver Laid Concrete Layers C11. 9 Finishing the Road and Road Reserve and Treating Old Roads C20. 1 Testing Materials and Judgement of Workmanship
Re- Advert: Appointment of a service provider for the supply and delivery of road maintenance material and plant as and when required for a period of 24 months
appointment of a service provider for supply, delivery and offloading of road and stormwater material as and when required for 24 months crusher run, crusher dust, concrete stone aggregate, concrete stone, gabions stones, interlocking pavement blocks, premixed concrete, cold mix asphalt, hot mix asphalt, emulsion, river sand, building sand, plastering sand, tipper, jet patcher, excavator, lowbed, grader, tlb, bidum, bomag roller, tack coat, cement, kerbstone, cover slabs, prefabricated concrete pipe culverts, portal units rectangular culverts, precast bases, culverts, catch pit cover, stop sign, yield sign, no entry sign, speed limit sign, pedestrians prohibited sign, pedestrian crossing sign, children crossing sign, gravel road begins sign, uneven road sign, speed humps sign, drift sign, tjunction chevron, temporary barricade, occasional flooding sign, deadend sign, danger plates, sharp curve chevron, galvanized pole, clamp piece, bolt, square tube, traffic cones, road markings
AI helper
The tender is for the appointment of a service provider for the supply, delivery, and offloading of road and stormwater material for 24 months. Bids must be submitted by March 23, 2026, at 12:00. The evaluation will be based on financial offer, preferences, and quality functionality. The preferential procurement policy framework act, ****, applies. Bidders must be registered on the central supplier database (CSD). The council reserves the right to not accept the lowest bid or any bid. Bids must be completed in black ink and valid for 90 days. The 80/20 point system will be used.
The bid notice states he expected turnaround time for delivery of the material is 5 working days after the purchase order has been issued.
Service providers will be paid in accordance with the emakhazeni local municipality supply chain management policy.
The evaluation, adjudication and awarding of this tender will be in terms of elm supply chain management policy which entails the balance between financial offer, quality and preferences on **** points system will be adopted.
The procedure for the evaluation of responsive bids will be on the average of the previous three projects where the firm was involved for similar projects.
The emakhazeni local municipality will if upon investigation it is found that a preference in terms of the act and these regulations has been obtained on a fraudulent basis, or any specified goals are not attained in the performance of the contract, on discretion of the municipal manager, one or more of the following penalties will be imposed: cancel the contract and recover all losses or damages incurred or sustained from the tenderer.
The value of this bid is estimated not to exceed r50 000 000 all applicable taxes included and therefore the **** point system shall be applicable.
Rehabilitation of Kerk and Nyala Street General requirements and provision Contractors establishment on site and general obligations Accommodation of traffic Housing, offices and laboratory for the engineers site personnel Mass earthworks Crushedstone base Breaking up existing pavement layers Patching and repairing edge breaks Prime coat Asphalt base and surfacing Road markings Testing materials and workmanship
AI helper
The tender is for the rehabilitation of Kerk and Nyala Street. The opening date for the tender offers is 24 February 2026 at 12:00. The 80/20 scoring method will apply in the evaluation of bids. The tenderers must score a minimum of 56 points for the bid to be eligible. A compulsory meeting will be held for all tenderers. The successful bidder will be required to fill in and sign a written contract form. Bids must be delivered by the stipulated time to the correct address. Late bids will not be accepted for consideration. The employer will provide the successful tenderer with one paper copy of the signed contract. The time for achieving practical completion is 6 months. The penalty for failing to complete the works is R1,**** per day. The payment period is within 14 days of receipt by the employer of the payment certificate signed by the employers agent.
The contract shall be completed twenty four months of the commencement within 24 date.
The employer shall pay the amount due to the contractor within 14 days of receipt by the employer of the payment certificate signed by the employers agent.
The defects liability period is 12 months from the date of completion on all new installations.
The **** scoring method will apply in the evaluation of bids.
Tenderers must score a minimum of 56 points for the bid to be eligible.
The penalty for failing to complete the works is R1,**** per day.
upgrade of utrecht street C1. 2. 8 dayworks personnel C1. 3. 1 the contractors general obligations C1. 4. 1 site accommodation offices and conference room C1. 5. 1 accommodation of pedestrian and non motorised traffic **** above C4. 3. 1 additional material investigations C5. 4. 2 chemical stabilisation: chemical stabilisation 150mm layer of **** rollerpass compaction of an exposed pavement layer smooth drum vibratory rollers **** watering the exposed pavement layer **** removal of surplus material from site **** insitu reconstruction of a pavement layer using a recycler to construct a stabilised base layer chemically stabilised base layer compacted to 100 of mdd **** material shortfall or makeup material for base layer **** finishing the stabilised layer slush reconstructed section with: water **** excavate pavement layers for patching in existing pavements excavate the following layers: cemented layers with a surface area: not exceeding 20 m, including for edge repa
AI helper
The tender is for the upgrade of Utrecht Street, including road rehabilitation, signage, and road markings. Bidders must submit bids by **** at 12:00. The 80/20 scoring method will be used. The time and location for opening of the tender offers are: 1200hrs date : 26 april 2026 location: abaqulusi local municipalitys boardroom co mark and high streets, vryheid, 3100. The contract will be completed within twelve months of the commencement within date. The offered total of the prices inclusive of value added tax is:. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . rand in words r . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . in figures. The employer shall pay the amount due to the contractor within 30 days of receipt by the employer of the payment certificate signed by the employers agent. The contractor shall commence with carrying out the works upon written instruction from the employers agent to commence with the works. The contractor will provide a payment certificate with quantities to the employers agent before or on the 20th of every month. After the payment certificate has been approved by employers agent, the contractor must issue an original tax invoice compliant with sars requirements for valid tax invoice. The date of the original tax invoice must be date the employers agent approved the payment certificate. The certificate will then be ready for handing in to the employer. Payment will be made end of the following month. The contractor shall provide a return in detail in the form and at such intervals as the employers agent or his duly authorized representative may prescribe showing the supervisory staff and the numbers of the several classes of labour from time to time employed by the contractor on the site and such information respecting constructional plant, equipment and material as the employers agent or his duly authorized representative may require. The targets for employment are as follows: women: 55 youth: 40. The definition of youth being of an age up to and including 35 years. The unit of measurement is person days being the total number of persons in that category multiplied by the number of days worked by each person respectively.
The contract shall be completed within welve months of the commencement within date.
The employer shall pay the contractor within 30 days of receipt by the employer of the payment certificate signed by the employers agent.
The 80/20 scoring method will apply in the evaluation of bids.
The tender offers will only be accepted if the tenderer is registered with the construction industry development board in the contractor grading designation of 6ce or higher.
The penalty for failing to complete the works is 0. 05 of the offered total of prices excluding vat per calendar day.
Add words related to your products or services. Our AI broadens the search so you don't miss opportunities.
2
Sign up and receive by email
Start the 14-day free trial and receive alerts with links to the documents and to the official page.
3
Adjust if needed
Add or edit keywords, set provinces, choose your delivery schedule and email style. A map view is available on the dashboard.
What our users say
90% recommend BidHits (1040 real users, 29/04/2026).Methodology
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
The idea of ​​using a keyword and sending the information by email is very good.
BidHits is a public tenders search engine. We map official portals daily and deliver results on the site and by email. Our AI understands your business so you don't miss opportunities.
Just enter your email and activate the trial. For 14 days you can use all features. When it ends, if you don't subscribe at /subscription.php, the tenders list becomes limited and there are no automatic charges.
1) Choose keywords (your products or services). 2) Activate the trial and start receiving. After signup you can adjust regions, times, and email style on the settings page.
Whenever possible, yes. Some official portals require login or block direct links; in those cases we point you to the official process page so you can download the documents.
Yes. In the tenders panel you can filter by region, procurement method, dates, and value ranges. In settings you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map in the panel and see tenders by location.
AI can make mistakes. It's trained to understand your business based on the keywords you add. Refine by adding specific terms, modifying or deleting those that produce off-topic results. That trains your feed and improves future alerts.
Yes. You can query tenders via API. Documentation at /api_integration.php. Ideal for CRM, BI and automations.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there's no auto-charge.
We monitor major official portals daily at the national, provincial and municipal levels. Tenders are added as soon as they are published on the source portal.
Plans start at R 710.00/month. Start with the free trial-- no automatic charges.
Explore a term, enable AI email alerts, access the tender documents or official portal, and filter by region and procurement method.
Transcript
Welcome to BidHits. Start by adding a few key words. Just type what you sell.
That's it. You're now ready to explore government contract opportunities made for you. Your bidding dashboard shows the latest tenders organized by date and matched to your keywords.
To help you spot the most relevant ones, your keywords are automatically highlighted in yellow.
And here's the best part. Our AI is always working behind the scenes to bring you even more opportunities.
Smart Search is already on, enhancing your results beyond exact matches. You don't have to do a thing.
Each tender card comes with useful tools. You can view a summary, open documents, favorite tenders, write private notes, remove what doesn't fit, or check the location on the map.
You can also see all tenders from the same day in a single map view. Perfect for planning your next steps. Use the search bar, apply filters, and explore with ease.
Try BidHits now. It's fast, smart, and free to get started.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1040 active users, conducted through 29/04/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
