Cap Press Tenders

The stipulated maximum time limit for practical completion is 153 days measured from the commencement date. The period to achieving practical completion starts from commencement date of the contract and is inclusive of 14 days to comply with clause 5. 3. 1, 14 days to allow employer to obtain construction work permit, and 153 days of construction period.

The bid notice states that SMME subcontractors are to be paid within thirty 30 days of receipt of invoice. Payment to SMMEs may be delayed pending payment of the main contractor by the employer. No interim payment of the SMME invoice may be unfairly withheld or delayed for whatever reason.

The latent defect period is ten 10 years, commencing on the day after the date of certification of practical completion.

Acceptable tenders will be evaluated using a system that awards points on the basis of tender price and the meeting of specific goals. Tenders will be adjudicated in terms of inter alia: compliance with tender conditions and technical specifications.

Tenderers shall answer questions regarding their familiarity with construction regulations, their approach to compliance, and provide details of proposed key persons, competent in terms of the regulations. CIDB registration proof and a COID letter of good standing are also required.

The O. R. Tambo District Municipality will impose penalties if a preference has been obtained on a fraudulent basis or if specified goals are not attained. Penalties may include contract cancellation, financial penalties, or restriction from obtaining future business. Specific penalties apply for failure to meet proposed direct participation of targeted enterprises and SMME subcontractor employment goals.

The bid notice lists Failure to attend compulsory site inspections as an action or error that is unacceptable and warrants rejection of the tender.

The bid notice mentions that materials or work which does not conform to the approved samples submitted in terms of clause 7. 4. 1 **** will be rejected. The employers agent reserves the right to submit samples to tests.

The bid notice states that the limit of referring the matter to the employers agent by the contractor shall be twenty-one 21 days after the decision in question was given by the employers agents representative.

The bid notice states, all equipment must come with their relevant product warranties. a minimum 5year warranty is required on the compressor of the ac unit.

The bid notice states, all proposal offers received shall be evaluated based on the following phase out approach: phase one: compliance to the terms of reference and conditions of the proposal. failure to meet any of the conditions of the proposal will automatically disqualify your proposal on this phase. phase two: preference points for broadbased black economic empowerment bbbee status level of contribution **** preference points system, where 80 points are allocated to price, and 20 points are allocated to bbbee status level as follows a bidder must obtain a minimum of 60 points on the prequalification phase in order to progress to the next phase.

The bid notice states, o ensure proper pricing and measurements are submitted at the time of quotation, service providers are required to attend the site meeting at the office and look at the scope of work before submitting their final quotation.

The bid notice states a firm delivery period must be indicated.

The bid notice states Payment terms are 30 days from date of invoice received date o as schedule 3a public entity: payments terms are 30 days from date of invoices should you be awarded.

The bid notice states he **** preference point system will be used where 80 points will be dedicated to price and 20 points to bbbee status.

The bid notice states The service provider must be sanas accredited for calibration.