Pressure Management Tenders

The stipulated maximum time limit for practical completion is 153 days measured from the commencement date. The period to achieving practical completion starts from commencement date of the contract and is inclusive of 14 days to comply with clause 5. 3. 1, 14 days to allow employer to obtain construction work permit, and 153 days of construction period.

The bid notice states that SMME subcontractors are to be paid within thirty 30 days of receipt of invoice. Payment to SMMEs may be delayed pending payment of the main contractor by the employer. No interim payment of the SMME invoice may be unfairly withheld or delayed for whatever reason.

The latent defect period is ten 10 years, commencing on the day after the date of certification of practical completion.

Acceptable tenders will be evaluated using a system that awards points on the basis of tender price and the meeting of specific goals. Tenders will be adjudicated in terms of inter alia: compliance with tender conditions and technical specifications.

Tenderers shall answer questions regarding their familiarity with construction regulations, their approach to compliance, and provide details of proposed key persons, competent in terms of the regulations. CIDB registration proof and a COID letter of good standing are also required.

The O. R. Tambo District Municipality will impose penalties if a preference has been obtained on a fraudulent basis or if specified goals are not attained. Penalties may include contract cancellation, financial penalties, or restriction from obtaining future business. Specific penalties apply for failure to meet proposed direct participation of targeted enterprises and SMME subcontractor employment goals.

The bid notice lists Failure to attend compulsory site inspections as an action or error that is unacceptable and warrants rejection of the tender.

The bid notice mentions that materials or work which does not conform to the approved samples submitted in terms of clause 7. 4. 1 **** will be rejected. The employers agent reserves the right to submit samples to tests.

The bid notice states that the limit of referring the matter to the employers agent by the contractor shall be twenty-one 21 days after the decision in question was given by the employers agents representative.

The bid notice states, Tenderers shall be evaluated on a **** preference point system in accordance with the msunduzi municipalitys supply chain management policy incorporating preferential procurement as prescribed in terms of the preferential procurement regulations 2022, pertaining to the preferential procurement policy framework act, act no. 5 of ****, including chapter 4 of the public procurement act no. 28 of 2024.

The bid notice states that if the delivery of the correct equipment is not met within 24 hours of the delivery date, penalties will be imposed on the contractor.

The bid notice states that transport tariffs must be given as a rate per kilometre and working tariffs as rate per hour. Tendered tariffs shall be value-added tax (VAT) inclusive.

The bid notice states that the municipality undertakes to hire plant according to the highest points obtained after calculation of points obtained that can do the required task.

The bid notice states that the minimum threshold on quality is 75 points, and all bidders below the minimum threshold will be disqualified.

The bid notice states that in the event of the municipality placing an order for an item of equipment with a contractor in writing, to be delivered to a site on a specific date and having confirmed in writing the availability of the specific item of equipment with the contractor prior to placing the order, the following penalties will be imposed on the contractor if the delivery of the correct equipment is not met within 24 hours of the delivery date.

The bid documents must be printed, completed and submitted before 12h00 on monday, 27 october 2025. his bid documents must be printed, completed andsubmitted before 12h00 on monday, 27 october 2025.

Bids will be evaluated and adjudicated in terms of greater giyanimunicipality supply chain management policy and preferential procurement policy framework act no 5of **** will be evaluated and adjudicated in terms of greater giyanimunicipality supply chain management policy and preferential procurement policy framework act no 5of ****.

Only service providers that are listed as accredited prospective provider on the central supplier database will be considered. only service provider that are listed as accredited prospective provider on the central supplier database will be considered