SOUTH AFRICA | FS
Fezile Dabi District Municipality
Contractor/ Windows
Appointment of a contractor for the upgrading of qalabotjha/villiers sports ground - refurbishment of ablution facilities
Rehabilitation and upgrade of Villiers Sports Ground Ablution Facility
AI helper
The anticipated commencement date for the contract is June 2026.
The conformity with EPWP requirements will together with contract price form the main criteria for the evaluation and adjudication of the tender.
Tenderers are required to submit details of their proposed conformance with EPWP requirements of employment, training and capacity building with their tenders.
Should the contractor remove or damage any tree marked to be preserved, a penalty of R200,00 per tree shall be payable.
The contractor shall furnish without delay such samples as may be called for by the engineer, who may reject all materials and workmanship not corresponding with the approved samples.
If the contractor fails to execute the works in accordance with the provisions of the contract the engineer may give notice in writing to the contractor to make good the failure, delay or default and should the contractor fail within seven 7 days to commence effective action to remedy the failure, delay or default then and in such case, the engineer shall without prejudice to any rights under the contract, and without invalidating the contract, be at liberty to take such work out of the contractors hands and contract with any person or persons to complete such work.
Tender Close Date:
